Sol rev 0002

Solicitation No.
140R4025R0017

Document Title
BGNDRF Yard Piping Upgrade

Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data-Modifications

CONTINUATION OF SECTION B – SUPPLIES OR SERVICES AND PRICES

Brackish Groundwater National Desalination Research Facility Yard Piping and Flow Measurement Upgrade Alamogordo, New Mexico
B.1

PRICE SCHEDULES (Section J – Attachment 12)
•

TO BE PROVIDED IN PHASE 2 ONLY

SECTION C – DESCRIPTION/SPECIFICATIONS

Please See Section J – Attachment 1 – Statement of Objectives (SOO)

SECTION D – PACKAGING AND MARKING

THIS PAGE INTENTIONALLY LEFT BLANK

SECTION E – INSPECTION AND ACCEPTANCE

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): Federal Acquisition Regulation: http://www.acquisition.gov/far/ RFO Part 52: https://www.acquisition.gov/far-overhaul/far-part-deviation-guide/far-overhaul-part-52 Department of the Interior Acquisition Regulation: https://www.acquisition.gov/diar

(End of clause)
Clause
52.246-12

CLAUSES INCORPORATED BY REFERENCE

Title
Date
Inspection of Construction
August 1996

SECTION F – DELIVERIES OR PERFORMANCE

52.211-12 LIQUIDATED DAMAGES – CONSTRUCTION (SEPT 2000) (RFO

DEVIATION OCT 2025)

(a) If the Contractor Fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,616.08 for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): Federal Acquisition Regulation: http://www.acquisition.gov/far/ RFO Part 52: https://www.acquisition.gov/far-overhaul/far-part-deviation-guide/far-overhaul-part-52