Attachment 2: Schedule of Items

SOUTHWEST REGION, R03

PRESCOTT NATIONAL FOREST

CHINO EMERGENCY REPAIRS

SCHEDULE OF ITEMS

2078182400875500

U.S. FOREST SERVICE

09/11/2026

1.0 SCHEDULE OF ITEMS

The following descriptions summarize the work for the Schedule of Items (SOI) listed below. They are not intended to be all-inclusive of the work needed to perform each item. Such work shall be considered incidental to the task and included in the final costs to perform the work.

1.1 ABBREVIATIONS

Pay Units
AC
Acre
LF
Linear Feet
CY
Cubic Yard, In-Place
LS
Lump Sum
EA
Each
MI
Mile
GL
Gallon
SF
Square Feet
HR
Hour
SY
Square Yard
LCY
Cubic Yard, Loose
TN
Ton

1.2 METHOD OF MEASURE DEFINITIONS

Actual (Contract) Quantity, AQ
The quantity to be paid is the quantity listed in the bid schedule. The contract quantity will be adjusted for authorized changes that affect the quantity or for errors made in computing this quantity. If there is evidence that a quantity specified as a contract quantity is incorrect, submit calculations, drawings, or other evidence indicating why the quantity is in error and request in writing that the quantity be adjusted.

Estimated (Design) Quantity, EQ
If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment to extend the completion date as, in the judgement of the Contracting Officer, is justified.

Lump Sum Quantity, LSQ
The bid amount is complete payment for all work described in the contract and necessary to complete the work for that pay item. The quantity is designated as "All". Estimated quantities of lump sum work shown in the contract are approximate.