Liquidated Damages CNNC FCA Corrections CONS

LIQUIDATED DAMAGES FORMULATION

Camp Nelson National Cemetery 833-030, Correct FCA Deficiencies 1. Estimated liquidated damages for NCA Contracting, Design & Construction Service (DCS), and Government-Retained Inspector are as follows. Civilian rates based on General Schedule Locality Pay Tables effective 01 Jan 2026.
Classification
NCA Contracting Officer
Legal Officer
DCS Project Manager
Govt Retained Inspector
Total Daily LD Amount

Grade
GS-13
NA
GS-14
GSA

Rate

Hours
$75
NA
$100
$150

Total
NA

$75
NA
$100
$1200
$1,375.00

2. The Contractor shall pay liquidated damages to the Government in the amount of $1,375.00 for each calendar day of delay until the work is completed or accepted. Numbers derived from historical trends associated with time required to perform additional contract administration. The purpose of Liquidated Damages is compensatory only. The Government retains the right to seek actual damages so far as they are distinguishable and separate due to Contractor not completing the work within the time specified in the contract.
3. Liquidated Damages as detailed above are in accordance with Federal Acquisition Regulation 36.206 and will be assessed for each calendar day required to complete the construction work on this project past the scheduled completion date.