Special Construction Clauses

SPECIAL CLAUSES FOR CONSTRUCTION

NFC-203-14 - DISPLAY OF HOTLINE POSTER(S) (JUN 2020)

Definition.

“United States,” as used in this clause, means the 50 States, the District of Columbia, and outlying areas.

Display of fraud hotline poster(s). Except as provided in paragraph (c)

During contract performance in the United States, the Contractor shall prominently display in common work areas within business segments performing work under this contract and at contract work sites.

Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this clause; and

Any DHS fraud hotline poster subsequently identified by the Contracting Officer.

Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall display an electronic version of the poster(s) at the website.

Any required posters may be obtained as follows:

Poster(s)
Obtain from
Defense Hotline Posters
http://www.dodhotline.dodig.mil/Hotline/posters.cfm

If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed $5.5 million, except when the subcontract

Is for the acquisition of a commercial item; or

Is performed entirely outside the United States.

(End of clause)

NFC-211-12 - LIQUIDATED DAMAGES – CONSTRUCTION (SEPT 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the NAFI in the amount of N/A for each calendar day of delay until the work is completed or accepted.

If the NAFI terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

NFC-222-36 - EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

(a) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.