Bid document

Tinker AFB

Tinker General Requirements

SECTION 01 32 16.00 20

SMALL PROJECT CONSTRUCTION PROGRESS SCHEDULES

PART 1

1.1

GENERAL

SUBMITTALS

Government approval is required for submittals with a "G" designation; submittals not having a "G" designation are for Contractor Quality Control approval. Submit the following in accordance with Section 01 33 00

SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals
Baseline Construction Schedule; G
Baseline Design Schedule; G
SD-07 Certificates
Monthly Updates
3-Week Look Ahead Schedule
1.2

PRE-CONSTRUCTION SCHEDULE REQUIREMENT

Within 10 calendar days of issuance of Notice to Proceed, prepare and submit to the Contracting Officer a Baseline Design Schedule and Baseline Construction Schedule in the form of a Network Analysis Schedule (NAS) or a Bar Chart Schedule (as directed by the Contracting Officer) in accordance with the terms in Contract Clause FAR 52.236-15 Schedules for Construction Contracts, except as modified in this contract. The approval of a Baseline Construction Schedule is a condition precedent to: a.

The Contractor starting demolition work or construction stage(s) of the contract.

b.

Processing Contractor's invoice(s) for construction activities/items of work.

c.

Review of any schedule updates.

Submittal of the Baseline Design and Construction Schedule, and subsequent schedule updates, is understood to be the Contractor's certification that the submitted schedule meets the requirements of the Contract Documents, represents the Contractor's plan on how the work will be accomplished, and accurately reflects the work that has been accomplished and how it was sequenced (as-built logic).
1.3
1.3.1

SCHEDULE FORMAT

Network Analysis Schedule (NAS)

Use the critical path method (CPM) to schedule and control project activities. Prepare and maintain project schedules using Microsoft Project. The scheduling software that will be utilized by the Government on this January 2022

Section 01 32 16.00 20

Tinker AFB

Tinker General Requirements

project is Microsoft Project by Microsoft, Inc. Notwithstanding any other provision in the contract, schedules submitted for this project must be prepared using Microsoft Project. Submission of data from another software system where data conversion techniques or software is used to import into Microsoft Projects scheduling software is not acceptable and will be cause for rejection of the submitted schedule.

1.3.1.1
a.

Activity Requirements

At a minimum, identify the following in the schedule: