Attachment 8: Liquidated Damages
Updated
A PDF document (82 KB) attached to WWYK250063 - Install React VII Facility, B9001, Post V19, from the Department of the Air Force. Due Nov 2, 2026, 2:00 PM (UTC-6).
File name: 250063_ATT 8_Liquidated Damages.pdf
The full file is for paid members, or buy this bid alone.
Preview
LIQUIDATED DAMAGES
PROJECT NUMBER & TITLE: WWYK250063 - INSTALL REACT VII FACILITY, B9001, POST V19
In accordance with FAR 36.206 and DFARS 236.206, liquidated damages (LDs) will be assessed for each calendar day of delay required to complete work on the subject contract/delivery order. As a minimum, LDs in the amount of $227.75 for each day thereafter will be changed based upon the following:
a. The contractor has complete control of the pace of work. b. The contract provides for LDs for delay of work for each calendar day of the contract. c. Considering the requirement, the rate of assessment is reasonable.
FACILITY/USER DAMAGES
Daily Consideration of Delivery Extension
Impact / Day
$
-
ENGINEERING TITLE
Engineering Manager
Project Manager
Engineering Tech, Inspector
Project Engineers
Clerical
SUBTOTAL
Hrs
0.5
0.5
0.5
GOVERNMENT TITLE
Hrs
0.5
FAS (GS-12/5)
Legal (GS-13/5)
Contracting (GS-12/5)
SUBTOTAL
$
$
$
$
$
$
$
$
RATE
57.69
36.06
28.52
38.46
19.41
$
$
$
$
$
$
TOTAL
28.85
36.06
28.52
19.23
9.71
122.36
RATE
39.19 $
46.60 $
39.19 $
$
TOTAL
19.60
46.60
39.19
105.39
$
227.75
TOTAL AMOUNT OF LIQUIDATED DAMAGES PER DAY - PHASE 1
Contracting Officer (Signature)
Contracting Officer (Print)
Date:
The beginning of the document. Download the full file to read on.